Terms & Conditions

Last Updated: April 1, 2026

Welcome to Lumipex Solar Solutions. By accessing and using our website, products, and services, you agree to comply with the following Terms & Conditions. Please read them carefully before using our website.

1. About Us

Lumipex is a women-led solar energy company specializing in the design, supply, installation, maintenance, and servicing of solar panel systems, including residential, commercial, and industrial solar solutions.

2. Website Usage

By using this website, you agree to:

• Use the website only for lawful purposes
• Provide accurate information in contact, quote, or service forms
• Not misuse, copy, or reproduce website content without permission
• Not attempt to disrupt website functionality or security
• Not use the website for fraudulent activities

3. Products & Services

All products and services displayed on this website, including:

• Solar Panels
• Rooftop Solar Systems
• On-Grid / Off-Grid Solar Solutions
• Solar Inverters
• Solar Batteries
• Annual Maintenance Services
• Solar Consultation

are subject to availability and may change without prior notice.

4. Pricing & Quotations

All prices, estimates, and quotations provided through the website are indicative only and may vary based on:

• Site inspection
• Roof size and structure
• Location
• Power requirements
• Government subsidy eligibility
• Material availability

Final pricing will be confirmed only after technical evaluation.

5. Installation & Service

Installation timelines may vary depending on:

• Site readiness
• Weather conditions
• Electricity board approvals
• Material delivery schedules
• Customer confirmation and advance payment

Lumipex will make every effort to complete projects within the committed timeline.

6. Warranty

Warranty terms for solar panels, inverters, batteries, and accessories will be as per the manufacturer’s warranty policy.

Installation workmanship warranty, if applicable, will be communicated separately in the project proposal or invoice.

7. Payment Terms

For project confirmation:

• Advance payment may be required
• Balance payment should be completed as per invoice milestones
• Delayed payments may affect delivery and installation timelines

8. Intellectual Property

All content on this website including:

• Logo
• Images
• Text
• Graphics
• Service descriptions
• Design elements

belongs to Lumipex and may not be copied, reproduced, or reused without written consent.

9. Limitation of Liability

Lumipex shall not be held responsible for:

• Indirect losses
• Power generation variation due to weather
• Delays caused by third-party approvals
• Government subsidy delays
• Electricity board policy changes
• Force majeure situations

10. Third-Party Links

Our website may include links to third-party websites for payment, financing, or informational purposes. We are not responsible for the content or policies of external websites.

11. Governing Law

These Terms shall be governed in accordance with the laws of India, and any disputes shall be subject to the jurisdiction of the courts in Chennai, Tamil Nadu.

12. Updates to Terms

Lumipex reserves the right to update or modify these Terms & Conditions at any time without prior notice. Continued use of the website means acceptance of updated terms.